Southern Seeding Service, Inc. v W.C. English, Inc., et al

Appellant's Reply Brief on Damages for Delay


A construction contract includes both a price escalation provision, by which unit prices would be adjusted if work was ongoing after the recited completion date, and a no-damages-for-delay provision. A price adjustment for work performed after the recited completion date, according to the terms of the contract, would not be "compensation for delay," which was prohibited by the contract. In the construction industry, delay damages are the costs to a contractor of not being able to perform compensable work productively and efficiently due to the delays of others. The requested price adjustment for work performed later in time was due to increased materials costs over time, not construction delays, so the price adjustment would not be "compensation for delay."

LOADING PDF: If there are any problems, click here to download the file.

Reference Info:Appellate Brief | State, 4th Circuit, North Carolina | United States

DISCLAIMER: Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Timothy Wyatt, Conner Gwyn Schenck PLLC | Attorney Advertising

Written by:


Conner Gwyn Schenck PLLC on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:

Sign up to create your digest using LinkedIn*

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.

Already signed up? Log in here

*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.