News & Analysis as of

Civil Remedies Construction General Business

Read Civil Remedies updates, alerts, news, and legal analysis from leading lawyers and law firms:

Recoverability of adjudication costs: "Can't hear Lulu no more"

by DLA Piper on

In this series we have already looked at Lulu v Mulalley and Wes Futures v Allen Wilson, following which we predicted that, while parties to adjudication would attempt to use the Late Payment Act to recover their costs of...more

Defence & Indemnity - October 2017: V. SURETY AND BOND ISSUES

by Field Law on

V. SURETY AND BOND ISSUES - A. The Alberta Court of Queen’s Bench holds surety liable under a performance bond for consequential damages suffered by an obligee as result of defaulting contractor. Vermilion & District...more

Michigan Court Of Appeals Holds That Contractor Who Failed To Timely Seek A Time Extension Is Barred From Contesting Liquidated...

by Pepper Hamilton LLP on

Abhe & Svboda, Inc. v. State of Michigan Department of Transportation, 2017 Mich. App. Lexis 1387 (August 29, 2017) - Contractor Abhe & Svboda, Inc. (“A&B”) entered into a contract with the Michigan Department of...more

Bound by your bargain

by Dentons on

During April 2015, the Court of Appeals (Civil Division) delivered its judgment in MT Hojgaard A/S v. E.ON Climate and Renewables UK Robin Rigg East Limited [2015] EWCA Civ 407....more

Is it wrong to confuse an arbitrator's failure to give reasons with the conduct of proceedings?

by Dentons on

Construction disputes in South Africa are typically subject to dispute resolution by arbitration. This is usually regulated by the Arbitration Act (the Act). Under the common law and section 28 of the Act, an arbitration...more

Pennsylvania Superior Court Widens the Net for Negligent Misrepresentation Claims Against Professionals

by Wilson Elser on

A recent ruling by Pennsylvania’s intermediate appellate court has expanded the scope of liability for negligent misrepresentation to include a class of potential defendants far beyond those expressly exposed under a prior...more

Who says you can’t choose between liquidated damages or actual damages?

by Snell & Wilmer on

In Colorado, courts enforce liquidated damages provisions if three elements are satisfied: (1) the parties intended to liquidate damages; (2) the amount of liquidated damages was a reasonable estimate of the presumed actual...more

Concurrent delay and the 'prevention principle'

by White & Case LLP on

In a judgment issued earlier this week, the English High Court considered whether a contract excluding any claim for an extension of time in respect of periods of concurrent delay caused time to be rendered "at large" due to...more

Washington Mechanic’s Liens: How Recent Changes Impact Contractors

Construction contracting is a complex business. Whether you are the owner, contractor, or general contractor on a project, your attention must shift between numerous moving parts, regulatory requirements, and deadlines as the...more

Enforcing Public Contracts against a Surety

This summer, the Washington Supreme Court ended a long dispute within the construction industry and issued an opinion finding that a performance bond is, in essence, an insurance contract. The court made clear that a public...more

Liquidated damages for sectional completion

by White & Case LLP on

In the recent English High Court case of Vinci Construction UK Ltd v. Beumer Group UK Ltd, the court considered whether liquidated damages were enforceable under a construction contract which provided for sectional...more

My Roof, My Rules: Arbitrators May Determine Their Own Jurisdiction When the Parties Delegate that Authority

An issue that repeatedly comes up in construction disputes is the scope of an arbitration agreement. Courts generally interpret agreements to arbitrate broadly, and, where the arbitrability of a specific claim has been at...more

Unlicensed Contractor Shoots for the Stars . . . Sputters on Takeoff

Elon Musk . . . Eccentric engineer. Technology billionaire. And, now, litigation bad ass. Frequent readers of the California Construction Law Blog know that we’ve talked about the importance of being properly...more

BIM before the English Courts

by White & Case LLP on

In a judgment released in August 2017, the UK High Court granted an interim injunction requiring a Building Information Modelling ("BIM") coordinator to provide access to a common data environment....more

California Court of Appeal: Inserting The Phrase “Ongoing Operations” In An Additional Endorsement Is Not Enough to Preclude...

In a victory for additional insureds, a California appeals court held, in Pulte Home Corp. v. American Safety Indemnity Co., Cal.Ct.App. (4th Dist.), Docket No. D070478 (filed 8/30/17), that an insurer’s denial of coverage...more

Sharply-Divided Washington Supreme Court Holds That Sureties, Like Insurers, Must Pay Attorney Fees to Prevailing Parties When...

by Pepper Hamilton LLP on

King Cnty. v. Vinci Constr. Grands Projets/Parsons RCI/ Frontier-Kemper, JV, No. 92744-8, 2017 Wash. LEXIS 743 (July 6, 2017) - King County contracted with three construction firms (collectively, “VPFK”) to construct a...more

Under Construction - September 2017

by Snell & Wilmer on

Welcome to the fall 2017 edition of our Under Construction newsletter. We hope your summer has left you relaxed and refreshed to make the final push to successfully finish out the remainder of the year. In this issue, we...more

Defence & Indemnity - August 2017: V. SURETY AND BOND ISSUES: Manitoba Housing and Renewal Corp. v. Able Eavestroughing Ltd., 2017...

by Field Law on

V. SURETY AND BOND ISSUES - A. Manitoba Court of Queen’s Bench finds CRA entitled to priority to “earned but unpaid” contract funds held by obligee (over the surety who had paid out labour and material payment bond claims...more

A primer for contractors: Getting paid -- fact or fiction?

by Hellmuth & Johnson PLLC on

As a contractor, getting paid for work completed isn't always as easy as collecting onsite or sending an invoice. Hellmuth & Johnson construction law attorney Blake Nelson answers fact or fiction when it comes to collections,...more

Ninth Circuit Finds Incorporation Of ICC Rules Into Arbitration Agreement Constitutes Clear And Unmistakable Evidence Of...

by Carlton Fields on

In a case involving three related contracts, only one of which contained an arbitration agreement, the Ninth Circuit has held that incorporation of the rules of the International Chamber of Commerce (ICC) into an arbitration...more

Ohio Appeals Court Holds That Contractor Who Seeks Application of HOOP Formula to Calculate Home Office Overhead Need Not Prove...

by Pepper Hamilton LLP on

Wood Elec., Inc. v. Ohio Facilities Constr. Comm’n, 10th Dist. Franklin No. 16AP-643, 2017-Ohio-2743, 2017 Ohio App. Lexis 1745 (May 9, 2017) - The Ohio Facilities Construction Commission (“OFCC”), together with a school...more

Fourth Circuit Affirms Dismissal of Contractor’s Complaint, Declining to Create ‘Ultra Vires’ or ‘Bias’ Exceptions to the...

by Pepper Hamilton LLP on

Balfour Beatty Infrastructure, Inc. v. Mayor and City Council of Baltimore, 2017 U.S. App. Lexis 7252 (4th Cir., April 25, 2017) - The United States Court of Appeals for the Fourth Circuit recently addressed whether the...more

A reminder why certainty in contracts is so important

by Dentons on

In the recent New South Wales Court of Appeal decision Port Macquarie-Hasting Council v Diveva, the Court considered the contractual interpretation of a renewal clause. The clause was phrased in general terms and did not...more

Access to Site Denied

by Dentons on

Can a contractor rely on a mandament van spolie to regain access to the site? Simply put, yes, but under careful advice. The mandament van spolie is a common-law remedy manifested by the deprivation of a right to...more

Indemnitor Owes Indemnity Even Where Indemnitee is Actively Negligent, California Court Holds

Indemnity provisions are one of the most fought over provisions in design and construction contracts. But while parties generally understand the intent behind indemnity provisions — that one party (the “indemnitor”) agrees to...more

314 Results
|
View per page
Page: of 13
Cybersecurity

Follow Civil Remedies Updates on:

"My best business intelligence,
in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up using*

Already signed up? Log in here

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.