KY Contractors Can Now Assert Claims for Negligent Misrepresentation Against an Architect Despite Absence of a Contract

by Cohen Seglias Pallas Greenhall & Furman PC

Design professionals doing business in Kentucky beware: the Kentucky Court of Appeals recently held that a contractor may pursue a negligent misrepresentation claim against an architect for delays to a project resulting from allegedly defective plans and specifications. The Court permitted the contractor’s tort claim despite the absence of a contractual agreement between the parties and the fact that the contractor signed documents that waived its claims. 

The case, D.W. Wilburn, Inc. v. K. Norman Berry Assocs., Architects, PLLC, No. 2015-CA-001254-MR, 2016 WL 7405774 (Ky. Ct. App. Dec. 22, 2016), involved construction work on a school owned by the Oldham County Board of Education (“the Board”). The Board hired D.W. Wilburn, Inc. (“Wilburn”) as the general contractor and K. Norman Berry Associates (“KNBA”) as the architect on the project. Throughout the course of the project, Wilburn executed 21 change orders that contained waiver and release language. Wilburn submitted a final payment application and signed closeout forms that also contained waiver language.

At the conclusion of the project, Wilburn’s electrical subcontractor brought a claim against Wilburn for delay to the project. In turn, Wilburn sued KNBA under a negligent misrepresentation theory, alleging that the project’s delay was caused by KNBA’s failure to properly prepare plans and specifications.

KNBA sought to have Wilburn’s claim dismissed, arguing that: (1) there was no contract between Wilburn and KNBA that would give rise to a claim; (2) Wilburn’s claims were barred by the economic loss rule, and; (3) waiver language in the change orders and final payment application barred Wilburn from asserting its claims against KNBA. The Circuit Court agreed with KNBA, and Wilburn appealed.

In addressing KNBA’s lack of contract argument, the Court of Appeals found that KNBA owed a duty to Wilburn independent of Wilburn’s contract with the Board. Therefore, Wilburn could maintain a claim that KNBA breached that duty by negligently issuing allegedly defective plans and specifications.

The Court likewise rejected KNBA’s reliance on the economic loss rule, which historically operates to prevent a party from seeking to recover under a tort claim for purely economic damages that should be recovered in a contract claim. In doing so, the Court reasoned that it is the very purpose of the claim to compensate for purely economic losses when there is no contractual remedy available but there is a breach of duty.

Finally, with respect to KNBA’s waiver argument, the Court held that the waivers executed by Wilburn released only claims against the Board and not against KNBA. The Court found that KNBA was not a party to the general contract, that the change orders themselves did not create a contractual relationship between KNBA and Wilburn, and that nothing in the change orders or final payment application waived or released a negligent misrepresentation claim against KNBA.

The Court of Appeals, therefore, reversed the lower court’s dismissal of Wilburn’s claim against KBNA and remanded the case for further proceedings. We will continue to track this case and its application in future cases. For now, the Court’s decision confirms that contractors can bring claims against design professionals for negligent misrepresentation notwithstanding the lack of a contractual agreement.

DISCLAIMER: Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Cohen Seglias Pallas Greenhall & Furman PC | Attorney Advertising

Written by:

Cohen Seglias Pallas Greenhall & Furman PC

Cohen Seglias Pallas Greenhall & Furman PC on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up using*

Already signed up? Log in here

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
Custom Email Digest
Privacy Policy (Updated: October 8, 2015):

JD Supra provides users with access to its legal industry publishing services (the "Service") through its website (the "Website") as well as through other sources. Our policies with regard to data collection and use of personal information of users of the Service, regardless of the manner in which users access the Service, and visitors to the Website are set forth in this statement ("Policy"). By using the Service, you signify your acceptance of this Policy.

Information Collection and Use by JD Supra

JD Supra collects users' names, companies, titles, e-mail address and industry. JD Supra also tracks the pages that users visit, logs IP addresses and aggregates non-personally identifiable user data and browser type. This data is gathered using cookies and other technologies.

The information and data collected is used to authenticate users and to send notifications relating to the Service, including email alerts to which users have subscribed; to manage the Service and Website, to improve the Service and to customize the user's experience. This information is also provided to the authors of the content to give them insight into their readership and help them to improve their content, so that it is most useful for our users.

JD Supra does not sell, rent or otherwise provide your details to third parties, other than to the authors of the content on JD Supra.

If you prefer not to enable cookies, you may change your browser settings to disable cookies; however, please note that rejecting cookies while visiting the Website may result in certain parts of the Website not operating correctly or as efficiently as if cookies were allowed.

Email Choice/Opt-out

Users who opt in to receive emails may choose to no longer receive e-mail updates and newsletters by selecting the "opt-out of future email" option in the email they receive from JD Supra or in their JD Supra account management screen.


JD Supra takes reasonable precautions to insure that user information is kept private. We restrict access to user information to those individuals who reasonably need access to perform their job functions, such as our third party email service, customer service personnel and technical staff. However, please note that no method of transmitting or storing data is completely secure and we cannot guarantee the security of user information. Unauthorized entry or use, hardware or software failure, and other factors may compromise the security of user information at any time.

If you have reason to believe that your interaction with us is no longer secure, you must immediately notify us of the problem by contacting us at In the unlikely event that we believe that the security of your user information in our possession or control may have been compromised, we may seek to notify you of that development and, if so, will endeavor to do so as promptly as practicable under the circumstances.

Sharing and Disclosure of Information JD Supra Collects

Except as otherwise described in this privacy statement, JD Supra will not disclose personal information to any third party unless we believe that disclosure is necessary to: (1) comply with applicable laws; (2) respond to governmental inquiries or requests; (3) comply with valid legal process; (4) protect the rights, privacy, safety or property of JD Supra, users of the Service, Website visitors or the public; (5) permit us to pursue available remedies or limit the damages that we may sustain; and (6) enforce our Terms & Conditions of Use.

In the event there is a change in the corporate structure of JD Supra such as, but not limited to, merger, consolidation, sale, liquidation or transfer of substantial assets, JD Supra may, in its sole discretion, transfer, sell or assign information collected on and through the Service to one or more affiliated or unaffiliated third parties.

Links to Other Websites

This Website and the Service may contain links to other websites. The operator of such other websites may collect information about you, including through cookies or other technologies. If you are using the Service through the Website and link to another site, you will leave the Website and this Policy will not apply to your use of and activity on those other sites. We encourage you to read the legal notices posted on those sites, including their privacy policies. We shall have no responsibility or liability for your visitation to, and the data collection and use practices of, such other sites. This Policy applies solely to the information collected in connection with your use of this Website and does not apply to any practices conducted offline or in connection with any other websites.

Changes in Our Privacy Policy

We reserve the right to change this Policy at any time. Please refer to the date at the top of this page to determine when this Policy was last revised. Any changes to our privacy policy will become effective upon posting of the revised policy on the Website. By continuing to use the Service or Website following such changes, you will be deemed to have agreed to such changes. If you do not agree with the terms of this Policy, as it may be amended from time to time, in whole or part, please do not continue using the Service or the Website.

Contacting JD Supra

If you have any questions about this privacy statement, the practices of this site, your dealings with this Web site, or if you would like to change any of the information you have provided to us, please contact us at:

- hide
*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.