Property Damage, Occurrences, Delays, Offsets and Fees. California Decision is a Smorgasbord of Construction Insurance Issues

by Wendel, Rosen, Black & Dean LLP
Contact

I read once that 97 percent of cases never go to trial. However, there are still the ones that do. And, then, there are the ones that do both. The following case, Global Modular, Inc. v. Kadena Pacific, Inc., California Court of Appeals for the Fourth District, Case No. E063551 (September 8, 2017), highlights some of the issues that can arise when portions of cases settle and other portions go to trial, the recovery of delay damages on a construction project through insurance, and the recovery of attorneys’ fees.

Global Modular, Inc. v. Kadena Pacific, Inc.

The U.S. Department of Veterans Affairs contracted with general contractor Kadena Pacific, Inc. (Kadena) to oversee construction of its Center for Blind Rehabilitation in Menlo Park, California. Kadena, in turn, contracted with subcontractor Global Modular, Inc. (Global) to construct, deliver and install 53 modular units totaling more than 37,000 square feet for a contract price of approximately $3.5 million.

Because Kadena had contracted with another subcontractor to install the roofing, Global agreed to deliver the units covered only by a roof deck substrate comprised of a three-quarter inch sheet of plywood. Delivery of the units was originally scheduled for the summer, however, due to project delays the units were not delivered until October and November.

Well, you can guess what happened.  The rains came and the units were damaged.

The Kadena-Global subcontract provided that Global would assume responsibility “for any loss or damage to the [units] . . . however caused, until final acceptance thereof by [Kadena].” The contract conditioned “final acceptance” upon the VA’s approval of the units. Kadena, however, as the general contractor, was responsible for the overall project schedule.

When Global refused to pay Kadena, Kadena sued, and Global countersued for the water damage. Before trial, the parties entered into a partial settlement. Global paid Kadena $321,975 except for claims covered by Global’s insurance policy with North American Capacity Insurance Company (NAC) and Global received $153,025 to dismiss  its failure-to-pay claims. At trial, Kadena presented evidence of its cost to repair the water damage and was awarded approximately $1 million.

In a separate action bought by NAC, Kadena and NAC filed competing motions for summary judgment on the issue of whether NAC’s policy required it to indemnify Global for the approximately $1 million award in the other action. The trial court ruled in favor of Kadena finding that the award was covered under the NAC policy. The trial court also ruled that the award should be offset by the $321,975 Global paid in settlement and that Global was liable to Kadena for $360,000 in attorney’s fees.

NAC, Kadena, and Global each appealed, with: (1) NAC arguing that the water damage was not covered under its policy; (2) Kadena arguing that $321,975 settlement paid by Global should not be offset; and (3) Global and NAC arguing that the $360,000 in attorney’s fees should not have been awarded to Kadena.

Messy enough for you?

The Appeal

NAC’s Argument That the Water Damage was Not Covered Under its Policy

On appeal, NAC, Global’s insurer, argued that the water damage was not covered under its policy. Typical of commercial general liability insurance policies, the policy covered “property damage” caused by an “occurrence,” which was defined as “an accident, including continuous or repeated exposure to substantially the same general harmful conditions.” From this broad occurrence-based coverage, the policy carved out a variety of exclusions.

One of those exclusions (Exclusion j(5)) excluded coverage for “[t]hat particular part of real property in which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the ‘property damage’ arises out of those operations.” NAC argued that the phrase “are performing operations,” refers to works in progress and that the exclusion applies when property damage occurs before construction is complete and, because Global had not yet completed installation of the units, the exclusion applied. Global, on the other hand, argued that the phrase “are performing operations” only applied to particular components Global was physically working on at the time of the property damage and, because the water intrusion occurred while Global  was not working on the units, the exclusion did not apply.

Another exclusion (Exclusion j(6)) excluded coverage for “[t]hat particular part of any property that must be restored, repaired or replaced because ‘your work’ was incorrectly performed on it.” NAC argued that, because Global inadequately waterproofed the units, Global’s “work” was “incorrectly performed” and the exclusion applied. Global, on the other hand, argued that the term “work” refers to a product, such as warped or uneven floors, not to a process like covering units with plastic tarps, and that even if its waterproofing efforts were ineffective, the “particular part” of the “work” that was “incorrectly performed” was the use of a plywood substrate not the interior parts of the units.

While acknowledging NAC’s argument that commercial general liability insurance policies “are not designed to provide contractors and developers with coverage against claims their work is inferior or defective,” the Court of Appeal stated, “the problem with NACs’ argument is that it is based on its view of the underlying policy of commercial general liability insurance and not on an application of the policy language to the facts of the case.” And, here, tarping the units, even if performed incorrectly or inadequately was not a part of Global’s “work.”

With respect to Exclusion j(5), the Court of Appeals concluded that the active, present tense construction of the policy language, “are performing operations,” indicated that the exclusion only applies to damage caused during physical construction activities and, because Global was not physically working on the units at the time of the water damage, the exclusion did not apply. With respect to Exclusion j(6), the Court held that the “only arguably defective components or parts of Global’s work are the plastic tarps, as they failed to keep the water out,” but “more importantly, there was no allegation the items for which Kadena sought repair and replacement costs – the drywall, insulation, framing, and ducting – were defective” (emphasis in original).

Result: Win for Global.

NAC’s Argument That Delay Damages Were Not Covered Under its Policy

On appeal, NAC further argued that the delay damages awarded for the 131 days Kadena spent remediating the water damage were not covered under its policy because it did not constitute “property damage”

The Court of Appeal disagreed stating, “contrary to NAC’s contention, delay damages arising from “property damage” fall under the insuring clause, which obligates NAC to ‘pay those sums that the insured becomes legally obligated to pay as damages because of . . . . ‘property damage’ to which this insurance applies'” (emphasis in original). While the policy does not define damages, held the Court, “courts generally interpret the term to mean payments made to compensate a party for direct and consequential injuries caused by the acts of another” and “[h]ere, the 131 days of remediation was time Kadena could have spent completing the project had the units’ interiors not been damaged. That delay constitutes a consequential loss (a loss occasioned by the water intrusion) and as such, is part of the damages NAC must pay ‘because of’ property damage.”

Result: Win for Global.

Global and NAC’s Argument that Attorney Fees Were Not Recoverable by Kadena

On appeal, NAC and Global argued that attorney’s fees were not recoverable by Kadena because Kadena had released its right to obtain attorneys’ fees under the terms of its settlement with Global.

Under Code of Civil Procedure sections 1033 and 1033.5, explained the Court of Appeals, attorneys’ fees can be claimed as costs if allowed under law or statute. Further explained the Court, the Kadena-Global subcontract included an attorneys’ fee provision stating that Global “expressly agrees” to pay the reasonable attorneys’ fees Kadena incurs in “enforcing any provision or obligation arising under the contract.” This provision, while a one-way attorneys’ fee provision permitting only Kadena to recover attorneys’ fees, became bilateral under Civil Code section 1717, which provides:

In any action on a contract, where the contract specifically provides that attorney’s fees and costs, which are incurred to enforce that contract, shall be awarded either to one of the parties or to the prevailing party, then the party who is determined to be the party prevailing on the contract, whether he or she is the party specified in the contract or not, shall be entitled to reasonable attorney’s fees in addition to other costs.

Because the settlement agreement was intended to resolve all of the parties disputes except for claims NAC would cover, the agreement obtained two provisions, one releasing “all claims” arising from the VA project and another carving out a limited subset of claims arising from the VA project that the parties were reserving for trial:

4.1.1 Notwithstanding the language of Civil Code section 1542 and waiver provided in Section 4.2 of this Agreement, it is the parties’ express intent and they so agree that this agreement does not release claims from the Project related to  property damage, personal injury, [loss] of use and other claims that are covered under the [NAC] insurance policies described in Section 4.9.1 of this Agreement, true and accurate copies of which are attached to this Agreement as Exhibits “A” and “B”

(emphasis in original).

Based on this language, held the Court of Appeals, the settlement agreement allows Kadena to pursue its water damage claim and, as the prevailing party, to seek attorneys’ fees as part of that claim.

Result: Win for Kadena.

Kadena’s Argument that the $321,975 Settlement Paid by Global Should Not be Offset

Finally, on appeal, Kadena argued that the $321,975 settlement paid by Global should not offset the $1 million damage award covered by NAC’s policy because the payment represented payment in exchange for Kadena’s release of claims other than its water damage claim. In support of its argument, Kadena pointed to the Kadena-Global settlement agreement which provided that the parties were agreeing to release all claims against one another except for claims from the project “related to” claims covered by NAC’s policy.

“The equitable concept of offset,” explained the Court of Appeals, “recognizes it is unfair to require a defendant to compensate a plaintiff twice for the same injury.” “Thus, to warrant offset, Global’s settlement payment to Kadena must have compensated Kadena for the same harm as the jury’s damage award.” But here, held the Court, the jury was instructed by the trial court that any awarded damages should be limited to damages related to water remediation only and not to defective workmanship or pre-rain delays.

Result: Win for NAC.

Isn’t it nice when everyone’s a winner?

Conclusion

Global Modular underscores that, while commercial general liability policies are not intended to serve as a warranty covering poor workmanship, they do cover “property damage” that “occurs” from poor workmanship. Further, the case clarifies that delay damages may be recoverable depending on the language of the insurance policy. And, finally, the case is serves as a reminder that when settling portions of a case, it is important to be clear what specific portions of a case are being settled, as parties may not seek damages for those settled portions, or an offset may apply.

Photo credit: CC0 Public Domain

[View source.]

DISCLAIMER: Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Wendel, Rosen, Black & Dean LLP | Attorney Advertising

Written by:

Wendel, Rosen, Black & Dean LLP
Contact
more
less

Wendel, Rosen, Black & Dean LLP on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
Custom Email Digest
- hide

JD Supra Privacy Policy

Updated: May 25, 2018:

JD Supra is a legal publishing service that connects experts and their content with broader audiences of professionals, journalists and associations.

This Privacy Policy describes how JD Supra, LLC ("JD Supra" or "we," "us," or "our") collects, uses and shares personal data collected from visitors to our website (located at www.jdsupra.com) (our "Website") who view only publicly-available content as well as subscribers to our services (such as our email digests or author tools)(our "Services"). By using our Website and registering for one of our Services, you are agreeing to the terms of this Privacy Policy.

Please note that if you subscribe to one of our Services, you can make choices about how we collect, use and share your information through our Privacy Center under the "My Account" dashboard (available if you are logged into your JD Supra account).

Collection of Information

Registration Information. When you register with JD Supra for our Website and Services, either as an author or as a subscriber, you will be asked to provide identifying information to create your JD Supra account ("Registration Data"), such as your:

  • Email
  • First Name
  • Last Name
  • Company Name
  • Company Industry
  • Title
  • Country

Other Information: We also collect other information you may voluntarily provide. This may include content you provide for publication. We may also receive your communications with others through our Website and Services (such as contacting an author through our Website) or communications directly with us (such as through email, feedback or other forms or social media). If you are a subscribed user, we will also collect your user preferences, such as the types of articles you would like to read.

Information from third parties (such as, from your employer or LinkedIn): We may also receive information about you from third party sources. For example, your employer may provide your information to us, such as in connection with an article submitted by your employer for publication. If you choose to use LinkedIn to subscribe to our Website and Services, we also collect information related to your LinkedIn account and profile.

Your interactions with our Website and Services: As is true of most websites, we gather certain information automatically. This information includes IP addresses, browser type, Internet service provider (ISP), referring/exit pages, operating system, date/time stamp and clickstream data. We use this information to analyze trends, to administer the Website and our Services, to improve the content and performance of our Website and Services, and to track users' movements around the site. We may also link this automatically-collected data to personal information, for example, to inform authors about who has read their articles. Some of this data is collected through information sent by your web browser. We also use cookies and other tracking technologies to collect this information. To learn more about cookies and other tracking technologies that JD Supra may use on our Website and Services please see our "Cookies Guide" page.

How do we use this information?

We use the information and data we collect principally in order to provide our Website and Services. More specifically, we may use your personal information to:

  • Operate our Website and Services and publish content;
  • Distribute content to you in accordance with your preferences as well as to provide other notifications to you (for example, updates about our policies and terms);
  • Measure readership and usage of the Website and Services;
  • Communicate with you regarding your questions and requests;
  • Authenticate users and to provide for the safety and security of our Website and Services;
  • Conduct research and similar activities to improve our Website and Services; and
  • Comply with our legal and regulatory responsibilities and to enforce our rights.

How is your information shared?

  • Content and other public information (such as an author profile) is shared on our Website and Services, including via email digests and social media feeds, and is accessible to the general public.
  • If you choose to use our Website and Services to communicate directly with a company or individual, such communication may be shared accordingly.
  • Readership information is provided to publishing law firms and authors of content to give them insight into their readership and to help them to improve their content.
  • Our Website may offer you the opportunity to share information through our Website, such as through Facebook's "Like" or Twitter's "Tweet" button. We offer this functionality to help generate interest in our Website and content and to permit you to recommend content to your contacts. You should be aware that sharing through such functionality may result in information being collected by the applicable social media network and possibly being made publicly available (for example, through a search engine). Any such information collection would be subject to such third party social media network's privacy policy.
  • Your information may also be shared to parties who support our business, such as professional advisors as well as web-hosting providers, analytics providers and other information technology providers.
  • Any court, governmental authority, law enforcement agency or other third party where we believe disclosure is necessary to comply with a legal or regulatory obligation, or otherwise to protect our rights, the rights of any third party or individuals' personal safety, or to detect, prevent, or otherwise address fraud, security or safety issues.
  • To our affiliated entities and in connection with the sale, assignment or other transfer of our company or our business.

How We Protect Your Information

JD Supra takes reasonable and appropriate precautions to insure that user information is protected from loss, misuse and unauthorized access, disclosure, alteration and destruction. We restrict access to user information to those individuals who reasonably need access to perform their job functions, such as our third party email service, customer service personnel and technical staff. You should keep in mind that no Internet transmission is ever 100% secure or error-free. Where you use log-in credentials (usernames, passwords) on our Website, please remember that it is your responsibility to safeguard them. If you believe that your log-in credentials have been compromised, please contact us at privacy@jdsupra.com.

Children's Information

Our Website and Services are not directed at children under the age of 16 and we do not knowingly collect personal information from children under the age of 16 through our Website and/or Services. If you have reason to believe that a child under the age of 16 has provided personal information to us, please contact us, and we will endeavor to delete that information from our databases.

Links to Other Websites

Our Website and Services may contain links to other websites. The operators of such other websites may collect information about you, including through cookies or other technologies. If you are using our Website or Services and click a link to another site, you will leave our Website and this Policy will not apply to your use of and activity on those other sites. We encourage you to read the legal notices posted on those sites, including their privacy policies. We are not responsible for the data collection and use practices of such other sites. This Policy applies solely to the information collected in connection with your use of our Website and Services and does not apply to any practices conducted offline or in connection with any other websites.

Information for EU and Swiss Residents

JD Supra's principal place of business is in the United States. By subscribing to our website, you expressly consent to your information being processed in the United States.

  • Our Legal Basis for Processing: Generally, we rely on our legitimate interests in order to process your personal information. For example, we rely on this legal ground if we use your personal information to manage your Registration Data and administer our relationship with you; to deliver our Website and Services; understand and improve our Website and Services; report reader analytics to our authors; to personalize your experience on our Website and Services; and where necessary to protect or defend our or another's rights or property, or to detect, prevent, or otherwise address fraud, security, safety or privacy issues. Please see Article 6(1)(f) of the E.U. General Data Protection Regulation ("GDPR") In addition, there may be other situations where other grounds for processing may exist, such as where processing is a result of legal requirements (GDPR Article 6(1)(c)) or for reasons of public interest (GDPR Article 6(1)(e)). Please see the "Your Rights" section of this Privacy Policy immediately below for more information about how you may request that we limit or refrain from processing your personal information.
  • Your Rights
    • Right of Access/Portability: You can ask to review details about the information we hold about you and how that information has been used and disclosed. Note that we may request to verify your identification before fulfilling your request. You can also request that your personal information is provided to you in a commonly used electronic format so that you can share it with other organizations.
    • Right to Correct Information: You may ask that we make corrections to any information we hold, if you believe such correction to be necessary.
    • Right to Restrict Our Processing or Erasure of Information: You also have the right in certain circumstances to ask us to restrict processing of your personal information or to erase your personal information. Where you have consented to our use of your personal information, you can withdraw your consent at any time.

You can make a request to exercise any of these rights by emailing us at privacy@jdsupra.com or by writing to us at:

Privacy Officer
JD Supra, LLC
10 Liberty Ship Way, Suite 300
Sausalito, California 94965

You can also manage your profile and subscriptions through our Privacy Center under the "My Account" dashboard.

We will make all practical efforts to respect your wishes. There may be times, however, where we are not able to fulfill your request, for example, if applicable law prohibits our compliance. Please note that JD Supra does not use "automatic decision making" or "profiling" as those terms are defined in the GDPR.

  • Timeframe for retaining your personal information: We will retain your personal information in a form that identifies you only for as long as it serves the purpose(s) for which it was initially collected as stated in this Privacy Policy, or subsequently authorized. We may continue processing your personal information for longer periods, but only for the time and to the extent such processing reasonably serves the purposes of archiving in the public interest, journalism, literature and art, scientific or historical research and statistical analysis, and subject to the protection of this Privacy Policy. For example, if you are an author, your personal information may continue to be published in connection with your article indefinitely. When we have no ongoing legitimate business need to process your personal information, we will either delete or anonymize it, or, if this is not possible (for example, because your personal information has been stored in backup archives), then we will securely store your personal information and isolate it from any further processing until deletion is possible.
  • Onward Transfer to Third Parties: As noted in the "How We Share Your Data" Section above, JD Supra may share your information with third parties. When JD Supra discloses your personal information to third parties, we have ensured that such third parties have either certified under the EU-U.S. or Swiss Privacy Shield Framework and will process all personal data received from EU member states/Switzerland in reliance on the applicable Privacy Shield Framework or that they have been subjected to strict contractual provisions in their contract with us to guarantee an adequate level of data protection for your data.

California Privacy Rights

Pursuant to Section 1798.83 of the California Civil Code, our customers who are California residents have the right to request certain information regarding our disclosure of personal information to third parties for their direct marketing purposes.

You can make a request for this information by emailing us at privacy@jdsupra.com or by writing to us at:

Privacy Officer
JD Supra, LLC
10 Liberty Ship Way, Suite 300
Sausalito, California 94965

Some browsers have incorporated a Do Not Track (DNT) feature. These features, when turned on, send a signal that you prefer that the website you are visiting not collect and use data regarding your online searching and browsing activities. As there is not yet a common understanding on how to interpret the DNT signal, we currently do not respond to DNT signals on our site.

Access/Correct/Update/Delete Personal Information

For non-EU/Swiss residents, if you would like to know what personal information we have about you, you can send an e-mail to privacy@jdsupra.com. We will be in contact with you (by mail or otherwise) to verify your identity and provide you the information you request. We will respond within 30 days to your request for access to your personal information. In some cases, we may not be able to remove your personal information, in which case we will let you know if we are unable to do so and why. If you would like to correct or update your personal information, you can manage your profile and subscriptions through our Privacy Center under the "My Account" dashboard. If you would like to delete your account or remove your information from our Website and Services, send an e-mail to privacy@jdsupra.com.

Changes in Our Privacy Policy

We reserve the right to change this Privacy Policy at any time. Please refer to the date at the top of this page to determine when this Policy was last revised. Any changes to our Privacy Policy will become effective upon posting of the revised policy on the Website. By continuing to use our Website and Services following such changes, you will be deemed to have agreed to such changes.

Contacting JD Supra

If you have any questions about this Privacy Policy, the practices of this site, your dealings with our Website or Services, or if you would like to change any of the information you have provided to us, please contact us at: privacy@jdsupra.com.

JD Supra Cookie Guide

As with many websites, JD Supra's website (located at www.jdsupra.com) (our "Website") and our services (such as our email article digests)(our "Services") use a standard technology called a "cookie" and other similar technologies (such as, pixels and web beacons), which are small data files that are transferred to your computer when you use our Website and Services. These technologies automatically identify your browser whenever you interact with our Website and Services.

How We Use Cookies and Other Tracking Technologies

We use cookies and other tracking technologies to:

  1. Improve the user experience on our Website and Services;
  2. Store the authorization token that users receive when they login to the private areas of our Website. This token is specific to a user's login session and requires a valid username and password to obtain. It is required to access the user's profile information, subscriptions, and analytics;
  3. Track anonymous site usage; and
  4. Permit connectivity with social media networks to permit content sharing.

There are different types of cookies and other technologies used our Website, notably:

  • "Session cookies" - These cookies only last as long as your online session, and disappear from your computer or device when you close your browser (like Internet Explorer, Google Chrome or Safari).
  • "Persistent cookies" - These cookies stay on your computer or device after your browser has been closed and last for a time specified in the cookie. We use persistent cookies when we need to know who you are for more than one browsing session. For example, we use them to remember your preferences for the next time you visit.
  • "Web Beacons/Pixels" - Some of our web pages and emails may also contain small electronic images known as web beacons, clear GIFs or single-pixel GIFs. These images are placed on a web page or email and typically work in conjunction with cookies to collect data. We use these images to identify our users and user behavior, such as counting the number of users who have visited a web page or acted upon one of our email digests.

JD Supra Cookies. We place our own cookies on your computer to track certain information about you while you are using our Website and Services. For example, we place a session cookie on your computer each time you visit our Website. We use these cookies to allow you to log-in to your subscriber account. In addition, through these cookies we are able to collect information about how you use the Website, including what browser you may be using, your IP address, and the URL address you came from upon visiting our Website and the URL you next visit (even if those URLs are not on our Website). We also utilize email web beacons to monitor whether our emails are being delivered and read. We also use these tools to help deliver reader analytics to our authors to give them insight into their readership and help them to improve their content, so that it is most useful for our users.

Analytics/Performance Cookies. JD Supra also uses the following analytic tools to help us analyze the performance of our Website and Services as well as how visitors use our Website and Services:

  • HubSpot - For more information about HubSpot cookies, please visit legal.hubspot.com/privacy-policy.
  • New Relic - For more information on New Relic cookies, please visit www.newrelic.com/privacy.
  • Google Analytics - For more information on Google Analytics cookies, visit www.google.com/policies. To opt-out of being tracked by Google Analytics across all websites visit http://tools.google.com/dlpage/gaoptout. This will allow you to download and install a Google Analytics cookie-free web browser.

Facebook, Twitter and other Social Network Cookies. Our content pages allow you to share content appearing on our Website and Services to your social media accounts through the "Like," "Tweet," or similar buttons displayed on such pages. To accomplish this Service, we embed code that such third party social networks provide and that we do not control. These buttons know that you are logged in to your social network account and therefore such social networks could also know that you are viewing the JD Supra Website.

Controlling and Deleting Cookies

If you would like to change how a browser uses cookies, including blocking or deleting cookies from the JD Supra Website and Services you can do so by changing the settings in your web browser. To control cookies, most browsers allow you to either accept or reject all cookies, only accept certain types of cookies, or prompt you every time a site wishes to save a cookie. It's also easy to delete cookies that are already saved on your device by a browser.

The processes for controlling and deleting cookies vary depending on which browser you use. To find out how to do so with a particular browser, you can use your browser's "Help" function or alternatively, you can visit http://www.aboutcookies.org which explains, step-by-step, how to control and delete cookies in most browsers.

Updates to This Policy

We may update this cookie policy and our Privacy Policy from time-to-time, particularly as technology changes. You can always check this page for the latest version. We may also notify you of changes to our privacy policy by email.

Contacting JD Supra

If you have any questions about how we use cookies and other tracking technologies, please contact us at: privacy@jdsupra.com.

- hide

This website uses cookies to improve user experience, track anonymous site usage, store authorization tokens and permit sharing on social media networks. By continuing to browse this website you accept the use of cookies. Click here to read more about how we use cookies.