Silence Is Not So Golden

by Williams Mullen

As illustrated in the recent decision issued by the Federal Circuit Court of Appeals in Bell/Heery, a Joint Venture v. United States, No. 2013-5002, 2014 WL 43892 (Fed. Cir. Jan. 7, 2014), a contractor must carefully articulate how the Government has breached a contract and be persistent in imploring the Government to cure its breach or otherwise formally respond.  

Background of Bell/Heery

The facts of Bell/Heery concerned the Federal Bureau of Prisons (“FBOP”) award of a $238,175,000 design-build contract to Bell/Heery, a Joint Venture (“BH”), in May 2007 to build a federal correctional institution in New Hampshire.  The contract required completion by June 10, 2010 at the risk of $8,000 a day in liquidated damages for each day of delay.

The key issues in Bell/Heery surrounded the work required by the Request for Proposal (“RFP”) for a “cut to fill” site, such that the contractor had to level the ground by excavating materials from one area of the site to fill lower areas of the site.  These cut-to-fill operations had to be performed in compliance with the requirements of the New Hampshire Department of Environmental Sciences (“NHDES”).  BH assumed a single-step, cut-to-fill operation in which it would transport cut materials directly to the final fill location without interruption.  Instead, NHDES limited BH to disturbing no more than 40 acres of land at any one time.  Rather than approve one plan for the entire Project, NHDES required a phased plan of operation, and ultimately imposed ten additional limits on BH’s plan. 

By written correspondence and during progress meetings, BH repeatedly notified FBOP of the impact on its operation, including potential delay, from not being able to perform the single-step operation that formed the basis of BH’s bid and which BH alleged was standard in the industry.  According to BH’s allegations, FBOP representatives did advise that BH “would be treated fairly … .”  Importantly, however, the Court cautioned that BH did not “refuse to proceed with construction under the restrictions imposed by the NHDES, nor did BH press the Government to directly intervene with the NHDES on BH's behalf.” 

Ultimately, BH submitted a Request for Equitable Adjustment (“REA”) seeking $7,724,885 for the impact on its cut-to-fill operation.  After FBOP’s Contracting Officer (“CO”) denied the REA, BH filed a lawsuit in the Court of Federal Claims based upon theories of breach of contract, breach of the implied duty of good faith and fair dealing, constructive change and cardinal change.  Upon motion by the Government, the Court of Federal Claims dismissed BH’s lawsuit for failure to state a claim upon which relief could be granted.  On appeal, the Federal Circuit Court of Appeals upheld the trial court’s ruling.  

Summary of Court’s Holdings in Bell/Heery

Breach of Contract – Permits and Responsibilities
The contract incorporated the FAR’s Permits and Responsibilities clause, which, the Government argued, controlled who was responsible under the contract for the costs of obtaining the necessary approval for the cut-to-fill work.  The Permits and Responsibilities clause provides in relevant part that the “Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, and regulations applicable to the performance of the work.”  48 C.F.R. § 52.236-7 (emphasis added).  While acknowledging that the Permits and Responsibilities clause “can be constrained by other contractual provisions that specifically limit the scope of the contractor's obligations for permitting requirements …,” ultimately the Court concluded that no such limitation existed in the FBOP-BH contract. 

In this regard, the contract contained three provisions of note:

  1. “ The Contractor shall perform the following in conjunction with the FBOP Project Management Team: (a) In preparing for the design for the project, consult with appropriate officials of the State or a political subdivision of a State, or both, in which the project is located and who would have jurisdiction over the project if it were not a project constructed or altered by a federal agency.”
  2. “[i]n preparing construction documents, the Contractor is to consult with appropriate officials of the State or a political subdivision of a State, or both, in which the project will be located, who would have jurisdiction if it were not constructed by a federal agency.”
  3. “[i]n no case are the comments or recommendations of these officials to be implemented into the developmental documents without the approval of the FBOP.”

(citing RFP § C.4(d)(1), 4(e) and Technical Design Guideline 01415(D) (emphasis added))

Based upon the foregoing provisions, Judge Mayer concluded in his dissenting opinion that, accepting well-pleaded factual allegations as true and making all reasonable inferences in BH’s favor, the contract could be read as requiring FBOP “to confer with local permitting authorities and to approve or not any recommendations made by them.”  The Court disagreed, however, finding that BH had failed to plead a breach of any contractual obligation by FBOP. 

In reaching its conclusion, the Court made two primary points.  First, the Court rejected BH’s argument that the requirement for approval of FBOP as a condition to implementation of comments or recommendations made by NHDES somehow created any FBOP duty with respect to BH’s obligations under the Permits and Responsibilities clause.  Second, the Court concluded that any duty of FBOP to consult “with the appropriate officials” applied only during the design phase, not during the preparation of construction documents.  Because BH did not make any allegations that FBOP refused to consult with NHDES during the design phase, but instead alleged that FBOP failed to consult during the “construction phase of the project”, the Court concluded that no breach of contract was alleged.  The Court reached this conclusion notwithstanding the dissent’s view that the alleged failure of FBOP to consult occurred when BH revised its phasing plan, including detailed drawings for its excavation and clearing plan—i.e., as part of the design process, not construction.

Breach of Contract – Changes Clause
The Court also rejected BH’s argument that the Government breached the FAR’s Changes clause, also incorporated into the contract.  See 48 C.F.R. § 52.243-4(a).  Central to the Court’s holding was the absence of any allegation that the CO ever ordered specific, additional work.  Instead, BH only alleged that the Government’s silence ratified the alleged changes to the work.  In rejecting this argument, the Court noted that “’[s]ilence in and of itself is not sufficient to establish a demonstrated acceptance’ of a contractual change by the Contracting Officer.” (quoting Harbert/Lummus Agrifuels Projects v. United States, 142 F.3d 1429, 1434 (Fed. Cir. 1998))

Constructive/Cardinal Change and Duty of Good Faith and Fair Dealing
The Court also dismissed BH’s remaining counts for constructive/cardinal change and breach of the implied duty of good faith and fair dealing.  The Court rejected the constructive change and cardinal change claims because it was the actions of NHDES, not FBOP, that resulted in modified cut-to-fill operations.  In addition, while acknowledging the well-established rule that “Implied in every contract is a duty of good faith and fair dealing …,” the court rejected BH’s claim of a breach of this duty because the “implied covenant, however, cannot ‘create duties inconsistent with the contract's provisions.’”  (quoting Precision Pine & Timber, Inc. v. United States, 596 F.3d 817, 831 (Fed. Cir. 2010)) 

Lessons Learned

There are several lessons that can be learned from the decision in Bell/Heery:

  • A contractor’s obligations under the Permits and Responsibilities clause may be limited by other contract provisions, but there remains the risk that a court will read the obligations of the Permits and Responsibilities clause broadly as did the Court in Bell/Heery.
  • Silence is not always golden.  As good as it is to be vigilant in notifying the Government of delays and the impact of delays, it may not be enough.  Contractors should act to obtain direction from the Government, in writing, to maximize the protection of the contractor’s rights and to obtain clarity as to the Government’s official position.
  • While the implied duty of good faith and fair dealing applies to every government contract, it cannot create obligations that are contrary to the express terms of the contract.



DISCLAIMER: Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Williams Mullen | Attorney Advertising

Written by:

Williams Mullen

Williams Mullen on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up using*

Already signed up? Log in here

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
Custom Email Digest
Privacy Policy (Updated: October 8, 2015):

JD Supra provides users with access to its legal industry publishing services (the "Service") through its website (the "Website") as well as through other sources. Our policies with regard to data collection and use of personal information of users of the Service, regardless of the manner in which users access the Service, and visitors to the Website are set forth in this statement ("Policy"). By using the Service, you signify your acceptance of this Policy.

Information Collection and Use by JD Supra

JD Supra collects users' names, companies, titles, e-mail address and industry. JD Supra also tracks the pages that users visit, logs IP addresses and aggregates non-personally identifiable user data and browser type. This data is gathered using cookies and other technologies.

The information and data collected is used to authenticate users and to send notifications relating to the Service, including email alerts to which users have subscribed; to manage the Service and Website, to improve the Service and to customize the user's experience. This information is also provided to the authors of the content to give them insight into their readership and help them to improve their content, so that it is most useful for our users.

JD Supra does not sell, rent or otherwise provide your details to third parties, other than to the authors of the content on JD Supra.

If you prefer not to enable cookies, you may change your browser settings to disable cookies; however, please note that rejecting cookies while visiting the Website may result in certain parts of the Website not operating correctly or as efficiently as if cookies were allowed.

Email Choice/Opt-out

Users who opt in to receive emails may choose to no longer receive e-mail updates and newsletters by selecting the "opt-out of future email" option in the email they receive from JD Supra or in their JD Supra account management screen.


JD Supra takes reasonable precautions to insure that user information is kept private. We restrict access to user information to those individuals who reasonably need access to perform their job functions, such as our third party email service, customer service personnel and technical staff. However, please note that no method of transmitting or storing data is completely secure and we cannot guarantee the security of user information. Unauthorized entry or use, hardware or software failure, and other factors may compromise the security of user information at any time.

If you have reason to believe that your interaction with us is no longer secure, you must immediately notify us of the problem by contacting us at In the unlikely event that we believe that the security of your user information in our possession or control may have been compromised, we may seek to notify you of that development and, if so, will endeavor to do so as promptly as practicable under the circumstances.

Sharing and Disclosure of Information JD Supra Collects

Except as otherwise described in this privacy statement, JD Supra will not disclose personal information to any third party unless we believe that disclosure is necessary to: (1) comply with applicable laws; (2) respond to governmental inquiries or requests; (3) comply with valid legal process; (4) protect the rights, privacy, safety or property of JD Supra, users of the Service, Website visitors or the public; (5) permit us to pursue available remedies or limit the damages that we may sustain; and (6) enforce our Terms & Conditions of Use.

In the event there is a change in the corporate structure of JD Supra such as, but not limited to, merger, consolidation, sale, liquidation or transfer of substantial assets, JD Supra may, in its sole discretion, transfer, sell or assign information collected on and through the Service to one or more affiliated or unaffiliated third parties.

Links to Other Websites

This Website and the Service may contain links to other websites. The operator of such other websites may collect information about you, including through cookies or other technologies. If you are using the Service through the Website and link to another site, you will leave the Website and this Policy will not apply to your use of and activity on those other sites. We encourage you to read the legal notices posted on those sites, including their privacy policies. We shall have no responsibility or liability for your visitation to, and the data collection and use practices of, such other sites. This Policy applies solely to the information collected in connection with your use of this Website and does not apply to any practices conducted offline or in connection with any other websites.

Changes in Our Privacy Policy

We reserve the right to change this Policy at any time. Please refer to the date at the top of this page to determine when this Policy was last revised. Any changes to our privacy policy will become effective upon posting of the revised policy on the Website. By continuing to use the Service or Website following such changes, you will be deemed to have agreed to such changes. If you do not agree with the terms of this Policy, as it may be amended from time to time, in whole or part, please do not continue using the Service or the Website.

Contacting JD Supra

If you have any questions about this privacy statement, the practices of this site, your dealings with this Web site, or if you would like to change any of the information you have provided to us, please contact us at:

- hide
*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.