How Sequestration May Impact Government Construction Contracts

by Baker Donelson

Pursuant to the Budget Control Act of 2011, sequestration is the process by which automatic across-the-board spending cuts are being imposed on government programs. Because Congress was unable to reach an agreement by its March 1, 2013 deadline to avoid these spending cuts, sequestration has become a reality, and government construction contractors need to consider how their existing contracts may be affected.

The most important thing for a government contractor to figure out is how its contract is being funded and the status of the funding for any work yet to be performed.

For existing fully funded contracts, if the funds have already been obligated and the project is expected to stay within its budget, then sequestration will likely not have a direct impact. The Anti-Deficiency Act, 31 U.S.C. §1341 et seq., prevents an agency from incurring obligations in excess of its available funds. As a result, the funding for a contract awarded prior to 2013 should already be obligated.

Sequestration, however, will likely have a large impact on incrementally funded contracts. Incrementally funded contracts are contracts for which an agency has permission to obligate only the current year's cost at the time of the contract award. The future funds are obligated annually in the subsequent years for work occurring in each fiscal year. As a result of the spending cuts, an agency may not have the funds to pay contractors for future phases of work. Sequestration could have a particularly large impact on construction contracts involving non-severable work. Agencies may choose to terminate a contract for convenience as an alternative to stop a project when the funds ultimately run out. Many government contracts have an Availability of Funds clause which limits the government’s liability to pay up to the amount funded. A contractor must be careful to meet the notice provisions required by these clauses when it considers stopping work. Depending on the clause’s language, the contractor may be entitled to additional compensation if it has no choice but to stop work due to lack of funding, including pursuing claims for delay damages.

Contractors also need to consider how sequestration will affect options under existing contracts. A contract option must be financed with funds for the fiscal year in which it is exercised. As a result, contract options exercised prior to 2013 should not be impacted by sequestration. For contract options scheduled for exercise after the start of sequestration, however, the necessary funds may not be available because of the 2013 sequestration spending cuts. Contractors that choose to perform work in anticipation of an option being exercised run the risk of not being compensated for their work. Agencies may also try to renegotiate options with contractors. It is important to learn if the agency has funding for option work that has been allocated to a particular contract before starting the work.

It is also important to consider how sequestration may affect contract modifications and claims. A modification or change order may not be issued unless there are funds appropriated and available to pay. A contractor should ask the agency to provide funding information before the extra work is performed in order to avoid being a “volunteer” who has no right to payment. In a similar fashion, funds to pay claims may be tougher to find. A contractor may end up having to take the claim through the disputes process to obtain payment from the Judgment Fund which is unaffected by sequestration.

Federal construction programs will be cut by several billion under the mandatory spending cuts that took place on March 1, 2013. The OMB Report to the Congress on Joint Committee Sequestration for Fiscal Year 2013 published on March 1, 2013 provides more detailed information about program-by-program spending cuts. There are a variety of ways that agencies may choose to deal with these reductions. Agencies may take unilateral action to reduce or return obligated funds that have not yet been spent if they do not consider the project critical. Specifically, agencies may reduce or "claw back" funds by relying on the "changes clause" (FAR 52.243) in government contracts or agencies may terminate all or part of a contract for convenience. Agencies may also choose to 'de-scope' contract performance through deductive change orders.


Government construction contractors need to look carefully at the funding status of their projects. Hard decisions may need to be made about stopping work when future funding is not in place. Will there be more public private partnerships as a result? No one has a crystal ball, but we may see PPPs as the path to the future.

DISCLAIMER: Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Baker Donelson | Attorney Advertising

Written by:

Baker Donelson

Baker Donelson on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up using*

Already signed up? Log in here

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
Custom Email Digest
Privacy Policy (Updated: October 8, 2015):

JD Supra provides users with access to its legal industry publishing services (the "Service") through its website (the "Website") as well as through other sources. Our policies with regard to data collection and use of personal information of users of the Service, regardless of the manner in which users access the Service, and visitors to the Website are set forth in this statement ("Policy"). By using the Service, you signify your acceptance of this Policy.

Information Collection and Use by JD Supra

JD Supra collects users' names, companies, titles, e-mail address and industry. JD Supra also tracks the pages that users visit, logs IP addresses and aggregates non-personally identifiable user data and browser type. This data is gathered using cookies and other technologies.

The information and data collected is used to authenticate users and to send notifications relating to the Service, including email alerts to which users have subscribed; to manage the Service and Website, to improve the Service and to customize the user's experience. This information is also provided to the authors of the content to give them insight into their readership and help them to improve their content, so that it is most useful for our users.

JD Supra does not sell, rent or otherwise provide your details to third parties, other than to the authors of the content on JD Supra.

If you prefer not to enable cookies, you may change your browser settings to disable cookies; however, please note that rejecting cookies while visiting the Website may result in certain parts of the Website not operating correctly or as efficiently as if cookies were allowed.

Email Choice/Opt-out

Users who opt in to receive emails may choose to no longer receive e-mail updates and newsletters by selecting the "opt-out of future email" option in the email they receive from JD Supra or in their JD Supra account management screen.


JD Supra takes reasonable precautions to insure that user information is kept private. We restrict access to user information to those individuals who reasonably need access to perform their job functions, such as our third party email service, customer service personnel and technical staff. However, please note that no method of transmitting or storing data is completely secure and we cannot guarantee the security of user information. Unauthorized entry or use, hardware or software failure, and other factors may compromise the security of user information at any time.

If you have reason to believe that your interaction with us is no longer secure, you must immediately notify us of the problem by contacting us at In the unlikely event that we believe that the security of your user information in our possession or control may have been compromised, we may seek to notify you of that development and, if so, will endeavor to do so as promptly as practicable under the circumstances.

Sharing and Disclosure of Information JD Supra Collects

Except as otherwise described in this privacy statement, JD Supra will not disclose personal information to any third party unless we believe that disclosure is necessary to: (1) comply with applicable laws; (2) respond to governmental inquiries or requests; (3) comply with valid legal process; (4) protect the rights, privacy, safety or property of JD Supra, users of the Service, Website visitors or the public; (5) permit us to pursue available remedies or limit the damages that we may sustain; and (6) enforce our Terms & Conditions of Use.

In the event there is a change in the corporate structure of JD Supra such as, but not limited to, merger, consolidation, sale, liquidation or transfer of substantial assets, JD Supra may, in its sole discretion, transfer, sell or assign information collected on and through the Service to one or more affiliated or unaffiliated third parties.

Links to Other Websites

This Website and the Service may contain links to other websites. The operator of such other websites may collect information about you, including through cookies or other technologies. If you are using the Service through the Website and link to another site, you will leave the Website and this Policy will not apply to your use of and activity on those other sites. We encourage you to read the legal notices posted on those sites, including their privacy policies. We shall have no responsibility or liability for your visitation to, and the data collection and use practices of, such other sites. This Policy applies solely to the information collected in connection with your use of this Website and does not apply to any practices conducted offline or in connection with any other websites.

Changes in Our Privacy Policy

We reserve the right to change this Policy at any time. Please refer to the date at the top of this page to determine when this Policy was last revised. Any changes to our privacy policy will become effective upon posting of the revised policy on the Website. By continuing to use the Service or Website following such changes, you will be deemed to have agreed to such changes. If you do not agree with the terms of this Policy, as it may be amended from time to time, in whole or part, please do not continue using the Service or the Website.

Contacting JD Supra

If you have any questions about this privacy statement, the practices of this site, your dealings with this Web site, or if you would like to change any of the information you have provided to us, please contact us at:

- hide
*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.