Repudiatory Breach of Contract in English Law: a Matter of Timing or the Eye of the Beholder?

by Pillsbury Winthrop Shaw Pittman LLP
Contact

Under English law, an innocent party faced with a serious breach of contract by its counterparty is in a difficult position. Whilst a reasonable time is allowed to decide whether to accept the breach, or terminate the contract and claim damages, it is not always clear what is a reasonable period for such decision-making. The answer often depends on the circumstances. Thus, a party weighing a termination for repudiatory breach must be alert to a number of potential pitfalls. It must not terminate prematurely, before the breach is serious enough to be considered repudiatory, or it may face a return allegation of a repudiatory breach causing damages. It must not postpone until it is too late, as it could lose the right to terminate on the basis of affirmation of the contract. Further, while the innocent party is making up its mind, the party in breach might cure it so that there is no longer a repudiatory breach to accept. A recent Court of Appeal ruling illustrates how complicated this decision can be.

Background

The Court of Appeal decision came in Telford Homes (Creekside) Limited v. Ampurius Nu Homes Holdings Ltd [2013] EWCA Civ 577 (23 May 2013). In October 2008, Telford, as the property developer and anticipated landlord, entered into an agreement regarding a series of leases on four commercial units to be constructed in a property development with Ampurius as investor and intended tenant. The leases were proposed to run for 999 years from completion of each block, with a target completion date of 21 July 2010 for two of the commercial blocks, and the remaining two blocks to be completed by 28 February 2011. Telford was to use its reasonable endeavours to complete the work by the target completion dates "or as soon as reasonably possible thereafter" and to carry out the work on the property with due diligence. Telford commenced work promptly on the blocks. Then in June 2009 it suspended work on the two blocks with the later target completion date, allegedly as the result of cash flow issues. Despite the parties entering into extensive correspondence and negotiations to try and resolve the situation, it was not clear when Telford could or would recommence work on the latter two units. Nevertheless, Telford maintained that it would ultimately recommence the work in due course and that the blocks would be completed, although late. This led on 22 October 2010 to Ampurius’s purported acceptance of what it characterized as Telford's repudiatory breach of the agreement in delaying the work on the two blocks, and on that basis Ampurius terminated the agreement. However, unknown to Ampurius, Telford had actually restarted work on those two blocks on 4 October 2010. Telford then denied it was in repudiatory breach and alleged that Ampurius was in repudiatory breach as the result of outstanding payments it owed, and Telford sought to terminate the agreement on this basis.

The Initial Decision

In Ampurius NU Homes Holdings Ltd v Telford Homes (Creekside) Ltd [2012] EWHC 1820 (Ch) (04 July 2012) Mr. Justice Roth found in the High Court in favour of Ampurius. He held that by at least the end of 2009, after work on the two delayed blocks had been suspended for some five months, Telford's breach of contract in failing to progress the work with due diligence had become sufficiently serious to be considered repudiatory. He also found Telford in breach of its contractual obligation to use its reasonable endeavours to complete the work by the target completion dates or as soon as reasonably possible thereafter, and that the breach had become repudiatory by at least July 2010. He concluded that the parties' agreement had envisaged, in effect, a single project involving all four blocks, and that it would frustrate the commercial purpose of the agreement if Ampurius had to lease only two blocks while the rest of the development was put on hold. The judge considered Telford’s recommencement of work before Ampurius terminated to be irrelevant, as Ampurius was unaware that the work had restarted when it decided to terminate.

Telford then appealed, contending that its breaches of its reasonable endeavours and due diligence obligations were not repudiatory and did not entitle Ampurius to terminate the agreements.

The Court of Appeal Speaks

Telford's principal arguments on appeal were that:

  1. the first-instance judge had not adequately analysed the benefit Ampurius was intended to receive under the agreement in order to decide whether the breaches had deprived it of at least a substantial part of that benefit;and
  2. the judge had not focused on the right date in assessing when the breaches became repudiatory, which Telford argued should have been the date when Ampurius purported to terminate the lease agreement.

Lord Justice Lewison rendered the leading judgment allowing Telford’s appeal. He found the Court must look at the position of the parties and the facts on the date of the purported termination of the contract both as to actual breaches as well as anticipatory ones. In his opinion, Mr. Justice Roth had been wrong to consider whether Telford's breaches were repudiatory at an earlier date. Rather, the first-instance judge should have assessed the nature and seriousness of the breaches on the date when Ampurius acted to terminate the agreement. His Lordship went on to identify the following relevant factors for consideration in determining whether Telford’s breaches were sufficiently serious to be repudiatory:

  1. the benefit Ampurius was intended to obtain from performance of the lease agreement; and
  2. the effect of the breach on Ampurius, including any financial loss, how much of the intended benefit had already been received, whether an award of damages would adequately compensate for any losses, whether the breach was likely to be repeated, whether compliance with the obligations under the agreements could or would be resumed, and whether the breach fundamentally changed the value of any future performance of outstanding obligations.

Ultimately, in Lord Justice Lewison's view, the length of delay in the completion of the two blocks was insignificant in contrast to the 999-year commercial lease terms during which Ampurius would enjoy the rents and profits from the units. Thus, Telford’s breaches did not deprive Ampurius of a substantial part of the benefit it was intended to receive under the leases. According to his Lordship, absent a time of the essence provision, delay would only amount to a repudiatory breach if and when it becomes so prolonged as to frustrate the contract. For example, on the facts here, there was no evidence that the market value of the commercial units declined significantly during the period of delay. Furthermore, another important consideration was the fact that Telford had actually taken steps to cure its accrued breaches of contract before Ampurius attempted to accept the breaches and terminate. His Lordship concluded that Telford’s breaches were not repudiatory at the time Ampurius purported to terminate.

In a supporting judgment, Lord Justice Tomlinson noted that in his opinion the court did not even need to consider or decide whether Telford’s breaches of contract had ever become repudiatory. In his view, since the delayed work had been recommenced and Telford's breaches cured before Ampurius’s purported termination, "there was no repudiatory breach then available for acceptance".

The judicial disagreement in this case, as to whether admitted breaches of a commercial agreement were repudiatory, vividly illustrates the difficulty that an innocent party, even when aided by legal counsel, will face in deciding whether and when such breaches become sufficiently serious to justify the risk inherent in terminating the contract and seeking damages. The Court of Appeal's judgment nevertheless does provide some useful guidance on the English law of repudiatory breach, including examples of how to determine whether a breach is sufficiently serious, when the determination as to the nature and seriousness of the breach should be made, and whether and when a repudiatory breach can be cured.

DISCLAIMER: Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Pillsbury Winthrop Shaw Pittman LLP | Attorney Advertising

Written by:

Pillsbury Winthrop Shaw Pittman LLP
Contact
more
less

Pillsbury Winthrop Shaw Pittman LLP on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up using*

Already signed up? Log in here

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
Custom Email Digest
Privacy Policy (Updated: October 8, 2015):
hide

JD Supra provides users with access to its legal industry publishing services (the "Service") through its website (the "Website") as well as through other sources. Our policies with regard to data collection and use of personal information of users of the Service, regardless of the manner in which users access the Service, and visitors to the Website are set forth in this statement ("Policy"). By using the Service, you signify your acceptance of this Policy.

Information Collection and Use by JD Supra

JD Supra collects users' names, companies, titles, e-mail address and industry. JD Supra also tracks the pages that users visit, logs IP addresses and aggregates non-personally identifiable user data and browser type. This data is gathered using cookies and other technologies.

The information and data collected is used to authenticate users and to send notifications relating to the Service, including email alerts to which users have subscribed; to manage the Service and Website, to improve the Service and to customize the user's experience. This information is also provided to the authors of the content to give them insight into their readership and help them to improve their content, so that it is most useful for our users.

JD Supra does not sell, rent or otherwise provide your details to third parties, other than to the authors of the content on JD Supra.

If you prefer not to enable cookies, you may change your browser settings to disable cookies; however, please note that rejecting cookies while visiting the Website may result in certain parts of the Website not operating correctly or as efficiently as if cookies were allowed.

Email Choice/Opt-out

Users who opt in to receive emails may choose to no longer receive e-mail updates and newsletters by selecting the "opt-out of future email" option in the email they receive from JD Supra or in their JD Supra account management screen.

Security

JD Supra takes reasonable precautions to insure that user information is kept private. We restrict access to user information to those individuals who reasonably need access to perform their job functions, such as our third party email service, customer service personnel and technical staff. However, please note that no method of transmitting or storing data is completely secure and we cannot guarantee the security of user information. Unauthorized entry or use, hardware or software failure, and other factors may compromise the security of user information at any time.

If you have reason to believe that your interaction with us is no longer secure, you must immediately notify us of the problem by contacting us at info@jdsupra.com. In the unlikely event that we believe that the security of your user information in our possession or control may have been compromised, we may seek to notify you of that development and, if so, will endeavor to do so as promptly as practicable under the circumstances.

Sharing and Disclosure of Information JD Supra Collects

Except as otherwise described in this privacy statement, JD Supra will not disclose personal information to any third party unless we believe that disclosure is necessary to: (1) comply with applicable laws; (2) respond to governmental inquiries or requests; (3) comply with valid legal process; (4) protect the rights, privacy, safety or property of JD Supra, users of the Service, Website visitors or the public; (5) permit us to pursue available remedies or limit the damages that we may sustain; and (6) enforce our Terms & Conditions of Use.

In the event there is a change in the corporate structure of JD Supra such as, but not limited to, merger, consolidation, sale, liquidation or transfer of substantial assets, JD Supra may, in its sole discretion, transfer, sell or assign information collected on and through the Service to one or more affiliated or unaffiliated third parties.

Links to Other Websites

This Website and the Service may contain links to other websites. The operator of such other websites may collect information about you, including through cookies or other technologies. If you are using the Service through the Website and link to another site, you will leave the Website and this Policy will not apply to your use of and activity on those other sites. We encourage you to read the legal notices posted on those sites, including their privacy policies. We shall have no responsibility or liability for your visitation to, and the data collection and use practices of, such other sites. This Policy applies solely to the information collected in connection with your use of this Website and does not apply to any practices conducted offline or in connection with any other websites.

Changes in Our Privacy Policy

We reserve the right to change this Policy at any time. Please refer to the date at the top of this page to determine when this Policy was last revised. Any changes to our privacy policy will become effective upon posting of the revised policy on the Website. By continuing to use the Service or Website following such changes, you will be deemed to have agreed to such changes. If you do not agree with the terms of this Policy, as it may be amended from time to time, in whole or part, please do not continue using the Service or the Website.

Contacting JD Supra

If you have any questions about this privacy statement, the practices of this site, your dealings with this Web site, or if you would like to change any of the information you have provided to us, please contact us at: info@jdsupra.com.

- hide
*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.