A Virginia Mechanic's Lien Refresher, Courtesy of Jack Bays

by Spilman Thomas & Battle, PLLC

In February 2013 the Supreme Court of Virginia handed down its decision in Jack Bays1, a mechanic’s lien lawsuit involving the landowner, several lenders, the general contractor and no fewer than eleven subcontractors. Although the decision broke no new ground with respect to the Virginia mechanic’s lien statutes, it is a good review of procedural issues and a reminder of the importance of thoroughly documenting work progress and communications with other parties in a construction project.

In this case, the landowner church’s financing efforts ultimately failed, notwithstanding the fact that construction on the $13 million project was well under way. When it was apparent the landowner would obtain no further financing, on September 28, 2007, Jack Bays, the general contractor, sent a written memorandum to all of the subcontractors informing them of delays in the financing approval process and advised them it would “stop all active work on the site until all payments are current.” Whether the general and subcontractors’ work on the job site after this date was in the nature of “demobilization” or continuing work on their respective construction contract obligations was the focus of the Supreme Court’s review of the trial court’s adjudication of the validity of the contractors’ mechanic’s liens.

Initially, the Court addressed the established jurisdictional rule that both the trustee and the beneficiary of a deed of trust are ‘necessary parties’ and must be made parties defendant in a mechanic’s lien suit. These parties must be included because they have “a substantial interest in being the given the opportunity to challenge the validity of the mechanic[s’] lien, or otherwise to litigate the elements of the lien.2 In this case, the landowner’s financing included a deed of trust in which several participating banks were described as “lenders” and which further described a “Trust Indenture” for the benefit of certain bondholders with the Glasser & Glasser law firm as trustee.3 The plaintiff in the mechanic’s lien suit joined Glasser as a party defendant but not the many bondholders. The Court rejected the argument that the bondholders were necessary parties to the litigation, holding that in the “present, limited context” of the mechanic’s lien statutes, the interests of the bondholders were adequately protected by their trustee.

The Court then turned to the appellants’ contention that Jack Bays had not filed its memorandum of mechanic’s lien in a timely manner and had improperly included in the amount claimed therein work outside the 150-day limit prescribed by statute. The Virginia statute requires a lien claimant to file its memorandum “not later than 90 days from the last day of the month in which he last performs labor or furnishes material, and in no event later than 90 days from the time such building . . . is completed, or the work thereon otherwise terminated.”4 Appellants argued that Jack Bays’ September 28, 2007 demobilization memorandum to the subcontractors marked the date on which work on the project was “otherwise terminated” under the statute, and therefore its recordation of a lien memo 92 days thereafter was untimely.

The Court noted that it was undisputed that the project was not complete on the date of Jack Bays’ September 28, 2007 memo and, further, that several subcontractors remained and performed contract work on site thereafter. Therefore, the Supreme Court held that the circuit court was not ‘plainly wrong’ in finding that Jack Bays’ 90-day time limit for filing its mechanic’s lien memorandum ran from the last day of September, 2007, not the date of its earlier demobilization memo.

Under the Virginia statute, a lien claimant is prohibited from including “sums due for labor or materials furnished more than 150 days prior to the last day on which labor was performed or material furnished to the job preceding the filing of [the mechanic’s lien memorandum].”5 In the first instance, this determination is a “factual inquiry” for the finder of fact, and the trial court held that although the date of Jack Bays’ memo did not mark the running of the 90 days for filing its mechanic’s lien memo, that date did fix the 150-day ‘look back’ period for inclusion of sums due.6 Again, the Court held that it was the appellants’ burden to show that this decision was “plainly wrong or without evidence to support it.” In addition to the trial testimony of its site superintendent, Jack Bays’ introduction of detailed invoices and an expert witness in construction accounting carried the day in the trial court. Although the factual inquiry was complicated by issues involving a stipulated sum contract agreement in contrast to a cost-plus contract, the Court upheld Jack Bays’ contention that its mechanic’s claim included no amounts for work prior to the 150-day period.

Next, the Court rejected a failure to mitigate damages argument, observing that “when it became apparent that additional funding would not be obtained, Jack Bays acted promptly and decisively.”

Although it affirmed all other findings by the trial court, the Supreme Court reversed the trial court’s order directing the landowner’s entire 22-acre tract be sold to satisfy “all of the liens.” The applicable Virginia statute ultimately enforces a mechanic’s lien by sale of the building on which work is done “and so much land therewith as shall be necessary for the convenient use and enjoyment thereof.”7 The Court noted not all liens at issue were mechanic’s liens and viewed the record as void of any evidence on whether the sale of the entire property was proper.

In summary, the Jack Bays decision is a good refresher on the procedures and proof required to prevail in a suit to enforce a mechanic’s lien and another reminder that counsel should advise a construction client to thoroughly document project work and communications with all parties in the project.

1Glasser & Glasser, PLC v. Jack Bays, Inc., 258 Va. 358, 741 S.E.2d 599 (2013).
2Jack Bays, 258 Va. at 371 quoting James T. Bush Constr. Co. v. Patel, 243 Va. 84, 88, 412 S.E.2d 703, 705 (1992).
3258 Va. at 365
4Virginia Code §43-4
5Virginia Code §43-4
6The Court rejected as contrary to the plain language of the statute the appellants’ contention that the fixing of this date constituted a “unitary” date applicable to all other lien claimants.
7Va. Code §43-3

Written by:

Spilman Thomas & Battle, PLLC

Spilman Thomas & Battle, PLLC on:

Readers' Choice 2017
Reporters on Deadline

"My best business intelligence, in one easy email…"

Your first step to building a free, personalized, morning email brief covering pertinent authors and topics on JD Supra:
Sign up using*

Already signed up? Log in here

*By using the service, you signify your acceptance of JD Supra's Privacy Policy.
Custom Email Digest
Privacy Policy (Updated: October 8, 2015):

JD Supra provides users with access to its legal industry publishing services (the "Service") through its website (the "Website") as well as through other sources. Our policies with regard to data collection and use of personal information of users of the Service, regardless of the manner in which users access the Service, and visitors to the Website are set forth in this statement ("Policy"). By using the Service, you signify your acceptance of this Policy.

Information Collection and Use by JD Supra

JD Supra collects users' names, companies, titles, e-mail address and industry. JD Supra also tracks the pages that users visit, logs IP addresses and aggregates non-personally identifiable user data and browser type. This data is gathered using cookies and other technologies.

The information and data collected is used to authenticate users and to send notifications relating to the Service, including email alerts to which users have subscribed; to manage the Service and Website, to improve the Service and to customize the user's experience. This information is also provided to the authors of the content to give them insight into their readership and help them to improve their content, so that it is most useful for our users.

JD Supra does not sell, rent or otherwise provide your details to third parties, other than to the authors of the content on JD Supra.

If you prefer not to enable cookies, you may change your browser settings to disable cookies; however, please note that rejecting cookies while visiting the Website may result in certain parts of the Website not operating correctly or as efficiently as if cookies were allowed.

Email Choice/Opt-out

Users who opt in to receive emails may choose to no longer receive e-mail updates and newsletters by selecting the "opt-out of future email" option in the email they receive from JD Supra or in their JD Supra account management screen.


JD Supra takes reasonable precautions to insure that user information is kept private. We restrict access to user information to those individuals who reasonably need access to perform their job functions, such as our third party email service, customer service personnel and technical staff. However, please note that no method of transmitting or storing data is completely secure and we cannot guarantee the security of user information. Unauthorized entry or use, hardware or software failure, and other factors may compromise the security of user information at any time.

If you have reason to believe that your interaction with us is no longer secure, you must immediately notify us of the problem by contacting us at info@jdsupra.com. In the unlikely event that we believe that the security of your user information in our possession or control may have been compromised, we may seek to notify you of that development and, if so, will endeavor to do so as promptly as practicable under the circumstances.

Sharing and Disclosure of Information JD Supra Collects

Except as otherwise described in this privacy statement, JD Supra will not disclose personal information to any third party unless we believe that disclosure is necessary to: (1) comply with applicable laws; (2) respond to governmental inquiries or requests; (3) comply with valid legal process; (4) protect the rights, privacy, safety or property of JD Supra, users of the Service, Website visitors or the public; (5) permit us to pursue available remedies or limit the damages that we may sustain; and (6) enforce our Terms & Conditions of Use.

In the event there is a change in the corporate structure of JD Supra such as, but not limited to, merger, consolidation, sale, liquidation or transfer of substantial assets, JD Supra may, in its sole discretion, transfer, sell or assign information collected on and through the Service to one or more affiliated or unaffiliated third parties.

Links to Other Websites

This Website and the Service may contain links to other websites. The operator of such other websites may collect information about you, including through cookies or other technologies. If you are using the Service through the Website and link to another site, you will leave the Website and this Policy will not apply to your use of and activity on those other sites. We encourage you to read the legal notices posted on those sites, including their privacy policies. We shall have no responsibility or liability for your visitation to, and the data collection and use practices of, such other sites. This Policy applies solely to the information collected in connection with your use of this Website and does not apply to any practices conducted offline or in connection with any other websites.

Changes in Our Privacy Policy

We reserve the right to change this Policy at any time. Please refer to the date at the top of this page to determine when this Policy was last revised. Any changes to our privacy policy will become effective upon posting of the revised policy on the Website. By continuing to use the Service or Website following such changes, you will be deemed to have agreed to such changes. If you do not agree with the terms of this Policy, as it may be amended from time to time, in whole or part, please do not continue using the Service or the Website.

Contacting JD Supra

If you have any questions about this privacy statement, the practices of this site, your dealings with this Web site, or if you would like to change any of the information you have provided to us, please contact us at: info@jdsupra.com.

- hide
*With LinkedIn, you don't need to create a separate login to manage your free JD Supra account, and we can make suggestions based on your needs and interests. We will not post anything on LinkedIn in your name. Or, sign up using your email address.